Sunshine Coast Council

ITT261

Saturday 14 November 2026 (E. Australia Standard Time)

Tuesday 08 December 2026 12:00 PM (E. Australia Standard Time)

Thursday 03 December 2026 12:00 PM (E. Australia Standard Time)

Tuesday 19 January 2027 (E. Australia Standard Time)

Sunshine Coast Council

54 First Ave
Maroochydore, Queensland 4558
Australia

https://www.sunshinecoast.qld.gov.au/

The Mayor and councillors work closely with the Executive Leadership Team and staff to deliver a range of plans and strategies that guide the delivery of major projects across the region, and council’s capital works program. Council remains committed to its vision for the Sunshine Coast: to be Australia’s most sustainable region – healthy, smart, creative.

The buyer has elected to have their personal and contact details hidden. These details will be revealed at the buyers discretion.

Sunshine Coast Council is seeking a suitably qualified Principal Contractor/s for the construction of sections of the Mooloolaba to Sunshine Coast University (M2U) shared pathway.

The works have been divided into the following Separable Portions:

- Separable Portion A - Stage 2 – Molakai Drive from Lady Musgrave Dr to Karawatha Dr Mountain Creek

- Separable Portion B - Stage 3 – Karawatha Drive from Molakai Dr to Golf Links Dr Mountain Creek

Respondents may submit a tender for one or both separable portions. Council reserves the right to award one or two Contractors.

The required date for Practical Completion of the Works is 30 June 2027 for both separable portions.

Please note: Stage 1 of the Mooloolaba to Sunshine Coast University (M2U) shared pathway construction is not included within the scope of this contract.

The scope of works includes but is not limited to:

- Pathway construction

- Kerb and Channel

- Stormwater drainage

- Raised pedestrian crossings

- New street lighting and traffic signal changes

- Pavement widening and asphalt resurfacing

- Tree removals and landscaping

- PUP service relocations and Coordination with PUP authorities

- Traffic and pedestrian management

- Site management including environmental, WH&S, Sub-contractor management

- Maintenance and defect liability period

The successful contractor will be required to supply all materials, plant, equipment, and labour necessary to undertake and complete all activities associated with the scope of works under this Contract. This includes performing all tasks, operations, and associated services required to deliver the works in accordance with the specified requirements and to a satisfactory standard.

Works must be carried out in a professional and safe manner that will minimise impact on pedestrians and traffic. Pedestrian access must be maintained around the works and provide safe connections to the adjoining footpath network.

General information on the Mooloolaba to University (M2U) Active Transport Corridor can be found on the Councils website.

Mooloolaba to University (M2U) Active Transport Corridor | Sunshine Coast Council

An Information Session will be held on site as per the details set out in Schedule 2 of the Invitation to Tender.

16

• Queensland
  1: Sunshine Coast

All Regions of Service locations are within Australia.

None...

None...